Hebrew | Francais

Search


> Hemdat Yamim

Shabbat Parashat Balak 5780

P'ninat Mishpat: Too Slow to Meet a Non-Deadline

(based on ruling 71098 of the Eretz Hemdah-Gazit Rabbinical Courts)

Case: The plaintiffs (=pl) hired the defendant (=def), an architecture company, to plan their house and gain municipal approval for the plans. Pl signed a contract and paid a 4,000 shekel first payment in Dec. 2010. The process of presenting designs proceeded slowly, and def put a new architect on the project in April 2011. After def cancelled a June 2011 meeting with pl with five minutes notice, pl notified def that he is letting def go. Pl is suing to recover the first installment and an additional 6,000 shekels for the delay def caused and the missed meeting (pl took off from work). Def counters that they did significant work and that according to the contract, only a break of six months is breach of contract; there are no deadline for the work to be completed (def has incentive to proceed, because payment is based on progress). Def are countersuing for the contract to be upheld, i.e., to allow them to finish the job or pay for it.

 

Ruling: Although def did not sign the contract, def composed it, and thus both sides relied on it regarding mutual obligations. Regarding workers, whatever oral agreements and understandings were in place at the time of the beginning of the work are binding (Shulchan Aruch, Choshen Mishpat 333:1).

Both sides explained the contract’s provision of six months as dealing with a scenario of “losing touch.” One cannot deduce from this that all other delays in progress are acceptable. While beit din accepts def’s claim that there is not an end point of the project because one never knows which delays will be forced on the architect by the owner or the authorities, there are still minimum standards for consistent work.

[Beit din analyzed in detail the schedule of meetings and the sketches that def sent to pl.] It appears that months went by with def making very little progress. Considering that there was not substantive denial of pl’s claim that he several times asked for meetings and was rebuffed, there are clear grounds for grievance. The new architect claimed that the work done by his predecessor was not viable, thereby returning the project back to close to the beginning. The fact that another two months went by until a meeting was set between def and pl and that it was then cancelled without notice, gave pl due cause to feel he was not being taken seriously and could not depend on timely progress. Therefore, def’s counterclaim to hold pl to the contract is rejected.

Although def did put in time and produce some results, pl deserves his first payment back. Regarding work stopped in the middle, whether the worker backed out, or the employer fired him with sufficient justification, the worker gets paid the amount of money he saved the employer by his work (ibid. 4). In this case, since pl’s new architect started from the beginning, which they had little choice about, considering that def enjoys copyright privileges to their plans and did not allow their use, def did not benefit from them, and all that was paid must be returned.

[We will omit the analysis, but] def must pay pl an additional 500 shekels for the damages that their negligence, and especially their not coming to the last meeting, caused.

Top of page
Print this page
Send to friend


Dedication

We daven for a complete and speedy refuah for:

 

Nir Rephael ben Rachel Bracha
Refael Yitchak ben Chana

Netanel Ilan ben Sheina Tzipora

Netanel ben Sarah Zehava

Meira bat Esther

Yair Menachem ben Yehudit Chana

Rivka Reena bat Gruna Natna

Lillian bat Fortune

Yafa bat Rachel Yente

Eliezer Yosef ben Chana Liba

Ro'i Moshe Elchanan ben Gina Devra

Esther Michal bat Gitel

Yehudit Sarah bat Rachel

 

Together with all cholei Yisrael

 

Hemdat Yamim is dedicated

to the memory of:

those who fell in wars

for our homeland

 

Eretz Hemdah's beloved friends

and Members of

Eretz Hemdah's Amutah

 

Rav Shlomo Merzel z”l
Iyar 10 5771

 

Rav Reuven Aberman z"l

 Tishrei 9     5776

 

Mr. Shmuel Shemesh  z"l
Sivan 17 5774

 

R' Eliyahu Carmel z"l

Rav Carmel's father

Iyar 8    5776

 

Mrs. Sara Wengrowsky

bat R’ Moshe Zev a”h.

Tamuz 10       5774

 

Rav Asher Wasserteil z"l

Kislev 9   5769

 

R'  Meir ben

Yechezkel Shraga Brachfeld z"l

&

Mrs. Sara Brachfeld z"l

Tevet 16 5780

  

R'  Yaakov ben Abraham & Aisha

and

Chana bat Yaish & Simcha

Sebbag, z"l

 

Rav Yisrael Rozen z"l
Cheshvan 13 5778

 

Rav Benzion Grossman z"l
Tamuz 23    5777

 

Rav Moshe Zvi (Milton)

Polin z"l

Tamuz 19     5778

 

R' Abraham Klein z"l

Iyar 18 5779

  

  Hemdat Yamim
is endowed by Les & Ethel Sutker
of Chicago, Illinois
in loving memory of
Max and Mary Sutker
and
Louis and Lillian Klein, z”l

 

site by entry.
Eretz Hemdah - Institute for Advanced Jewish Studies, Jerusalem All Rights Reserved | Privacy Policy. | Terms of Use.