Hebrew | Francais

Search


> > Archive

Shabbat Parashat Korach 5779

P'ninat Mishpat: Firing a Contractor part IV

(based on ruling 75104.2 of the Eretz Hemdah-Gazit Rabbinical Courts)

Case: Plaintiff 2 (=pl2) was the contractor for major renovations of the defendant’s (=def) home; plaintiff 1 (=pl1) was the supervisor. Pl2 was well behind schedule and was fired by def. [Over the last three installments, we presented that def had the right to fire pl2, determined how to appraise the amount pl2 should receive for the work already done, and discussed a variety of damages. We continue with damages that are not damages to a specific object but are more general.] Def claims around 20,000 shekels for being forced to live in a house that was in poor condition for a long time, which caused great discomfort and psychological distress. She also demands 10,000 shekels for the job being finished late and 2,800 shekels for the delay in preparing the adjacent housing unit, which earns 2,800 shekels a month rent.  

 

Ruling: Regarding living in a home that was in disrepair for a long time, we generally accept the description of the difficulties. On the other hand, we must point out that with a relatively minor advancement of pay to other workers after deciding that pl2 would not continue, def could have solved most of the serious problems. Her decision not to do so should not obligate pl2 to pay. We also generally do not levy payments for causing distress. Therefore, the compensation to def for not getting the job done at the time that it should have will be addressed within consideration of how much pl2 deserves for the work that he did do.

Regarding the loss of income from the housing unit that was delayed in being constructed, we say the following. The halacha, regarding whether damage payments are due for preventing one from receiving profits that he was hoping for, is complicated (see a survey in Eretz Hemdah-Gazit’s ruling 70072). Some poskim say that if the profits could be relied upon without the need for any special skill or good luck, then one who prevents this “sure thing” is obligated (see Machaneh Ephrayim, Ribbit 41). Because the sides signed our arbitration agreement, which gives beit din the authority to obligate payment even in cases of lost profits when it views this as just, we decide to obligate pl2 for half of the month of lost rent that def claims. Regarding the delay in being able to move back to the home, since the sides did not set a payment schedule and def did not specify actual monetary damage that emerged from it, we will not require payment.

Top of page
Print this page
Send to friend


Dedication

We daven for a complete and speedy refuah for:

 

Nir Rephael ben Rachel Bracha

Refael Yitchak ben Chana
Netanel Ilan ben Sheina Tzipora 

Netanel ben Sarah Zehava

Yehuda ben Chaya Esther

Meira bat Esther

Yair Menachem ben Yehudit Chana

Rivka Reena bat Gruna Natna

David Chaim ben Rassa

Lillian bat Fortune

Yafa bat Rachel Yente

Eliezer Yosef ben Chana Liba

Ro'i Moshe Elchanan ben Gina Devra

 

 

Together with all cholei Yisrael

 

Hemdat Yamim is dedicated

to the memory of:

those who fell in wars

for our homeland

Eretz Hemdah's beloved friends

and Members of

Eretz Hemdah's Amutah

Rav Shlomo Merzel z”l
Iyar   10

Rav Reuven Aberman z"l

Tishrei 9 5776


Mr. Shmuel Shemesh  z"l
Sivan 17 5774

R' Eliyahu Carmel z"l

Rav Carmel's father

Iyar 8 5776


Mrs. Sara Wengrowsky

bat R’ Moshe Zev a”h.

Tamuz 10   5774


Rav Asher Wasserteil z"l

Kislev 9 5769

R'  Meir ben

Yechezkel Shraga Brachfeld z"l


R'  Yaakov ben Abraham & Aisha

and

Chana bat Yaish & Simcha

Sebbag, z"l


Rav Yisrael Rozen z"l
Cheshvan 13, 5778


Rav Benzion Grossman z"l
Tamuz 23 5777

 

Rav Moshe Zvi (Milton)

Polin z"l

Tammuz 19, 5778

 

Leiser Presser

ben R'Aharon Yitzhak and Bracha

on the occasion of his yahrzeit, 24 Iyar,

and members of his family

who perished in the shoah

Al Kiddush Hashem.

 

R' Abraham Klein z"l

18 Iyar 5779

 

Hemdat Yamim
is endowed by Les & Ethel Sutker
of Chicago, Illinois
in loving memory of
Max and Mary Sutker
and
Louis and Lillian Klein, z”l

site by entry.
Eretz Hemdah - Institute for Advanced Jewish Studies, Jerusalem All Rights Reserved | Privacy Policy. | Terms of Use.